Tag:Delay Damages and Bonus

1
FIDIC Update: The Employer’s Claim to Liquidated Damages and Performance Security under the Yellow Book

FIDIC Update: The Employer’s Claim to Liquidated Damages and Performance Security under the Yellow Book

By Camilla de Moraes, K&L Gates, London

The English courts have recently considered a number of cases involving the FIDIC suite of contracts (see here, here, and here for our previous blog posts).  The most recent case of J Murphy & Sons Ltd v Beckton Energy Ltd [2016] EWHC 607 (TCC)arises out of a contract based on FIDIC Conditions of Contract for Plant and Design Build for Electrical and Mechanical Plant and for Building and Engineering Works designed by the Contractor First Edition 1999 (FIDIC Yellow Book) with amendments.

The court was required to consider the relationship between two clauses in the Contract, namely Sub-Clause 2.5 (Employer’s Claims) and Sub-Clause 8.7 (Delay Damages and Bonus) with reference also to Sub-Clause 3.5 (Determinations) and 4.2 (Performance Security).  The issue in dispute was whether determination by the Engineer of the contractor’s liability for liquidated damages was a pre-requisite to recovery of liquidated damages by the Employer.  The court held that the clause entitling the Employer to liquidated damages operated outside of the regime in Sub-Clause 2.5 and therefore the Engineer’s determination was not a pre-requisite to the Employer’s entitlement.  This case also confirms the traditionally held view that obtaining injunctive relief preventing a beneficiary from calling on a performance bond will rarely be possible.

Read More

Copyright © 2024, K&L Gates LLP. All Rights Reserved.